These Terms and Conditions (“Terms”) govern your access to and use of the website of Kodegrid Solutions, available at https://www.kodegrid.com (referred to hereinafter as the “Website”). By using this Website, you agree to be bound by all the Terms set out below in full. If you do not agree with any part of these Terms, you must not use this Website.
Please read these Terms carefully before using our services.
Intellectual Property Rights
All intellectual property rights in the content, code, design, graphics, logos, and other material on this Website are owned by or licensed to Kodegrid Solutions. All rights are reserved. You are granted a limited, non-exclusive, non-transferable license to view and interact with the material on this Website for personal or business reference purposes only.
You must not reproduce, duplicate, copy, republish, sell, or distribute any content from this Website for commercial purposes without our express written consent. The Website design and elements may not be copied or imitated, in whole or in part, without prior authorization.
All custom graphics, icons, interface elements, and branding that appear on the Website are the trademarks or service marks of Kodegrid Solutions, or its affiliates and must not be used without express written permission.
While we permit downloading and printing of content for internal, non-commercial use within your organization, all copyright and proprietary notices must be retained in such copies.
Restrictions
By accessing this Website, you agree that you will not use it:
- In any way that causes, or may cause, damage to the Website or impair its performance or availability;
- In any manner that violates any applicable laws or regulations;
- To engage in any data mining, data harvesting, data extraction or any other similar activity;
- To copy, distribute, or commercially exploit the content without written permission;
- To transmit or post any harmful or malicious content including viruses, spyware, or other destructive programs.
Application Development Policy
Each application or software development project with Kodegrid Solutions is governed by a formal agreement. In cases where no explicit agreement or Terms of Use have been defined, the following policy applies:
If a project is not completed as per the originally agreed scope and delivery milestones, Kodegrid Solutions may offer a partial refund. The amount refunded will be calculated based on the percentage of work completed, as determined by our internal project evaluation team.
Dedicated Hiring Policy
If a project is delayed due to a failure on the part of our assigned developers or staff, we offer a full refund for the delayed start period. However, if the project is already in progress, refunds are only provided proportionally for any unutilized time.
If you’re unsatisfied with the performance of a dedicated resource, please inform the assigned Project Manager immediately. Refund negotiations will not be entertained after a project or milestone has been marked as complete.
Delivery and Responsibility
Clients are required to make timely payments as agreed upon in the project scope. Failure to do so may lead to project delays or termination.
It is the client’s responsibility to provide clear, timely, and accurate information. Any project delay or misalignment caused due to insufficient communication or incomplete inputs from the client will not be the responsibility of Kodegrid Solutions.
Unless otherwise specified in a signed agreement, we are not obligated to provide compensation for delays in delivery.
Termination of Services
Either party (you or KodeGrid) may end a service agreement. However, to be eligible for a refund, the termination request must be made within the first 7 working days and before the work has substantially started.
If a project is already underway or near completion, refunds will not be issued. Only unused portions of the service, if any, will be considered for a refund.
Cancellation & Refund Policy
We aim to keep things transparent and fair. If you’re not fully satisfied with our service, we offer a 3-working-day refund window — because your trust matters.
Governing Law
Regardless of your location, these Terms shall be governed by and construed in accordance with the laws of India, without regard to its conflict of law principles (see the official Ministry of Law and Justice, Government of India for details on Indian legislation). You agree to submit to the exclusive jurisdiction of the courts located in New Delhi, India for any dispute arising under or in connection with these Terms; more information about the jurisdiction of New Delhi courts can be found on the Delhi High Court Official Website.
Business Relationships and External Links
This Website may include links to third-party websites. Kodegrid Solutions is not responsible for the content, accuracy, or reliability of any linked websites. Accessing third-party links is at your own risk.
Disclaimer and Limitation of Liability
Unless otherwise agreed in a signed contract, all products and services provided through this Website are offered “as is” without warranties of any kind. We do not guarantee that the Website will be available at all times or free of errors, bugs, or security vulnerabilities.
To the fullest extent permissible by applicable law, Kodegrid Solutions disclaims all liability for any loss, damage, or inconvenience caused as a result of your use of this Website or any linked external sites. This includes direct, indirect, special, or consequential damages such as lost profits, business interruption, or loss of data.
Indemnification
You agree to indemnify, defend, and hold harmless Kodegrid Solutions, its affiliates, and employees from and against any claims, liabilities, losses, damages, or expenses arising out of your breach of these Terms or misuse of the Website.
Modifications to Terms
Kodegrid Solutions may revise, update, or replace these Terms at any time without prior notice. By continuing to use the Website, you agree to be bound by the most current version. We recommend that you review this page periodically to stay informed of any changes.
If you have any questions regarding these Terms & Conditions, please contact us at info@kodegrid.com.
